E(2)(2)(3) Calculation of the interest for the third part of the
The loan is the first phase................................... 75
E(2)(2)(4) The third part of the loan – the second phase........... 81
E(2)(2)(5) Summary of the reference to the amounts of the debt by virtue of the second agreement..... 86
e(2)(3) Consequences of non-compliance with the provisions of the Third Agreement regarding a delay................... 87
(3) Whether the plaintiffs are entitled to claim the offset of the contractor's debts to them in respect of
Late delivery and exemption from interest for the late period.......................................... 94
E(3)(1) Whether the defendants are "a single business economic entity"............................... 95
E(3)(2) The status of the waiver of claims..................................................... 101
E(3)(3) The claims regarding the defendants' liability for the delay in completing the project................ 113
The Ottoman Settlement [Old Version] 1916E(4) Interest for the period from 2019 to the present................................................... 122
12-34-56-78 Chekhov v. State of Israel, P.D. 51 (2)F. Summary and Legal Expenses.................................................................................................... 143
- General
- Defendants1-2 loaned money to members of a "purchasing group", including the plaintiffs, in order to finance a residential construction project. Defendant 3, which is a company related to defendants 1-2, was responsible for carrying out the construction work for the class members. As part of the lawsuit, the plaintiffs petition to declare the amount of each plaintiff's debt to the defendants.
- The parties disagree on a number of issues, including:
(-) whether the plaintiffs are liable for the balance of the debt of all the members of the class, or is each of them only responsible for a proportional portion of the total debt;
(-) whether the amount of the total debt and its distribution among the class members, as approved by the class board in 2020, has binding status, or can the plaintiffs dispute them;